Baker & O'Brien, Inc.

Experience

Experience

 

Case Attribute: Industry Practice/Standard of Care

Article
Air Emissions Dispute
Reviewed air emissions data and categorized events; provided understanding and analysis to air events with respect to process equipment and refinery and chemical plant operations.
Environmental , Industry Practice/Standard of Care , Product Quality
Ammonia Manufacturing Litigation
Assisted an equipment manufacturer in defending allegations that its equipment was the cause of a multi-million dollar business interruption claim.  Assisted in discovery, evaluated operating records, estimated business interruption losses due to a power outage, and provided expert testimony. 
Business Interruption , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Ammonia Plant Insurance Dispute
Assisted in evaluating insurance claims asserted by a major ammonia manufacturer.  Work included evaluation of the technical basis for claims involving construction defects and warranty work amounting to $3 million.  Assisted in documenting claims, inspected the plant, evaluated project records, and reviewed maintenance records.  
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Ammonia Plant Project Finance
Served as independent engineer on behalf of a major European bank for the relocation of a 750 TPD ammonia plant.  Work included an assessment of existing and new technology that was to be incorporated in the project.  The due diligence investigation analyzed feedstock supply, reviewed contracts, and inspected progress prior to close of financing.  Monitored construction progress, certified mechanical completion, and witnessed the plant performance test.  
Commercial Terms Review , Industry Practice/Standard of Care , Operations/Maintenance
Ammonia Plant Project Finance
Served as independent engineer on behalf of a major European bank for the construction of a new world-scale ammonia plant. Prepared a technology assessment, analyzed feedstock supply, reviewed contracts, and advised with negotiation of contracts. Monitored construction progress and mechanical completion, and witnessed the plant performance test.
Industry Practice/Standard of Care , Operations/Maintenance
Ammonia/Urea Plant Failure Analysis
Worked in support of client and its attorneys to investigate the cause of a reactor failure and defend against claims by OSHA and third parties.  Work involved extensive analysis of process equipment and operating practices used in ammonia and urea manufacture. 
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related
Asbestos Exposure Litigation
Assisted a manufacturer of industrial equipment in defending personal injury claims related to asbestos exposure.  Assisted in discovery, assessed the likelihood and degree of employee exposure to asbestos during maintenance activities, and reviewed equipment specifications, project histories, and maintenance records for various power generation units.  Provided opinions regarding the potential for personal injury due to asbestos exposure in the course of normal work activities.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety , Toxic Tort
Benzene Exposure
Assessed possibility of employee exposures to benzene during prior refinery operations.  Reviewed plant operating history and emissions records and provided preliminary opinions regarding potential benzene exposure to plaintiffs.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related
Business Interruption Damages Claim by Concrete Supplier
Assisted in a dispute between a concrete products producer and marketer against an oil refiner for damages allegedly incurred as a result of an incident at the oil refinery.  Examined the timeline of the incident and provided an independent damage estimate.  
Business Interruption , Industry Practice/Standard of Care , Operations/Maintenance
Business Interruption
Performed an analysis of the schedule delay and financial impact from chemical plant downtime due to a major equipment fabrication error.
Business Interruption , EPC-related , Industry Practice/Standard of Care , Safety
Business Interruption and Construction - Refining
Monitored engineering and construction efforts undertaken to rebuild production facilities damaged by fire.  The engagement was to ascertain the appropriate construction period for business interruption claim purposes and to facilitate the incident root cause analysis.  Activities included daily site inspections, regular consultations with plant engineering and construction personnel, progress assessments, and development of independent project schedules.
Industry Practice/Standard of Care , Operations/Maintenance
Caustic Soda Contract Dispute
Reviewed caustic soda plant expansion and the ability of supplier to deliver the required volume of caustic soda under contract.  Advised on the reasonableness of the expansion construction schedule based on review of environmental permits, public data, and internal documents on construction activities.
EPC-related , Industry Practice/Standard of Care
Chemical Plant Accident Investigation
Investigated an accident at a polyethylene production and storage facility. Reviewed equipment design, inspection and repair history, training of personnel, industry practices, and standards of care.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Chemical Plant Evaluation
Provided an independent assessment at a chemical plant of recent maintenance and sustaining capital projects.
Industry Practice/Standard of Care , Operations/Maintenance
Class Action Environmental Litigation
Provided assistance in evaluating environmental issues which led to a neighborhood lawsuit. Reviewed plant operating and emissions history and provided preliminary opinions regarding the potential for future impact on local community.
Environmental , Industry Practice/Standard of Care , Operations/Maintenance
Commercial Contract Litigation
Assisted in a claim related to a force majeure incident related to the recommissioning of a facility after a hurricane.  Examined conformance with standard industry protocols and applicable laws, standards, and regulations.  Assessed whether the facility operator acted in a reasonably prudent manner with respect to the commercial and technical issues necessary to safely restart the facility as soon as possible.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Condensate Feedstock Contract Dispute
Assisted in a claim between: (1) a European refiner and ultimate condensate supplier, and (2) an intermediary company, concerning allegations that the intermediary company was prevented from obtaining condensate supplies for sale to the refiner.  Studied the potential availability and quality of condensates in the producing region and elsewhere.  Identified potentially suitable condensates for the refinery.  Based on forecasts of oil and petroleum product prices, prepared an estimate of potential economic damages.  Described how term feedstock contracts for condensate are typically concluded.  Testified at an arbitration in London.
Arbitration , Expert Witness/Testimony , Industry Practice/Standard of Care , Pricing
Construction Dispute - Gas Plant
Provided expert reports and testimony regarding project management issues, alleged defects, and liquidated damages for international arbitration between owner and contractor.  The project involved an offshore platform, an undersea pipeline, an onshore pipeline, an onshore cryogenic gas processing plant, and a sales gas pipeline.
Arbitration , EPC-related , Expert Witness/Testimony , Gasification , Industry Practice/Standard of Care , Offshore , Pipeline
Construction Dispute - Petrochemicals Plant
Prepared a confidential "Cold Eyes Review" assessment concerning a contemplated claim between an owner and a contractor of a grassroots petrochemical facility.  Reviewed draft claims, researched evidence, and interviewed key personnel in order to produce an independent view of the claim.
EPC-related , Industry Practice/Standard of Care
Construction Dispute Litigation - Gas Plant
Assisted in a litigated dispute between Owner-Operator and Engineering & Construction Contractor over whether a cryogenic gas plant, as engineered, procured, and constructed, met the stipulated contractual performance guarantees; prepared expert witness rebuttal report with respect to relevant issues.
EPC-related , Expert Witness/Testimony , Gasification , Industry Practice/Standard of Care , Operations/Maintenance
Contractual Dispute
Performed a due diligence of owner allegations and contractor claims pertaining to a Lump Sum-Turn Key contract termination.  Reviewed documents, schedules, witness statements, and expert reports to advise counsel on implications of contracting strategy and contract management following award.
EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care
Cost Allocation Report
Following a refinery fire incident and rebuild, performed an analysis of all elements of the repair costs, and produced a report that assessed and allocated repairs into three categories:  identical replacement, functional replacement, and upgrade.
Industry Practice/Standard of Care , Operations/Maintenance , Physical Asset Appraisal , Pricing
Crude Oil Metering Dispute
Investigated alleged tampering with crude oil Automatic Custody Transfer volume and quality measuring devices.  Reviewed common carrier pipeline tariffs, inspected site, and analyzed measurement data.
Industry Practice/Standard of Care , Pipeline , Product Quality
Crude Oil Sludge Accumulation
Following a claim concerning sludge accumulation in crude oil storage tanks over a twenty-year period, advised as to the creation of sludge in crude oil tanks, its accumulation, the ways to prevent or control it, and the conventional ways of dealing with it.
Industry Practice/Standard of Care , Operations/Maintenance , Product Quality
Damages from Steam Turbine Failure
Assisted in determining economic damages resulting from failures associated with a new steam turbine that was provided and installed by a turbine manufacturer at a power generation facility. Conducted independent assessment of economic losses suffered by electric cooperative as a result of both short-term and long-term performance shortfalls and outages.
Business Interruption , EPC-related , Industry Practice/Standard of Care , Operations/Maintenance , Pricing
Defective Product Lawsuit
Provided an expert report concerning a dispute between a pressure safety relief device manufacturer and an operator of a claim that a device did not operate as designed in a reactor overpressure incident.
Forensic Analysis , Industry Practice/Standard of Care , Operations/Maintenance
Defend Wastewater Treater Air Emissions
Requested to provide expert witness opinion of industrial standard of care for wastewater treater operations.  Issue concerned volatile organic compound (VOC) emissions from a wastewater treater feed tank.
Industry Practice/Standard of Care , Operations/Maintenance
Delayed Coker Fire Investigation
Assisted client in investigating the cause of a coker hydrocarbon release and fire, which resulted in multiple fatalities. Visited refinery and reviewed procedures and events preceding the incident to identify potential areas of causation and liability. Operating experience and knowledge of technical and safety issues and of industry and management practices helped the client in addressing specific claims issues.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Due Diligence of Gas Gathering and Processing Assets
Conducted due diligence on gas gathering and processing assets within the Permian Basin in Southeast New Mexico and West Texas on behalf of lending group and prospective purchaser. Conducted physical inspection of the facilities, reviewed operation and maintenance records, assessed gas supply and competitive position, and reviewed financial assumptions and projections to ensure consistency with current gas supply contracts and asset performance.
Industry Practice/Standard of Care , Operations/Maintenance , Physical Asset Appraisal , Pricing
Dust Collection System Risk Assessment
Performed a quantitative risk assessment on a dust collection system associated with the multifolder process at a large paper products manufacturing facility. Purpose was to determine if OSHA stipulations were appropriate.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Economic Damages Litigation - Plant Explosion
Retained concerning claims of design errors and failures in project management, following explosions and fires at a petrochemical plant.  Conducted in-depth reviews of engineering, procurement, and construction agreements; process technology and design basis; construction records; owner's operating procedures; and actual operating history since start-up of the plant.  Evaluated operating system provided against prevailing industry standards and examined potential for equipment failure.
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Economic Damages Litigation - Plant Fire
Following furnace damage and rebuild, provided expert regarding property damage costs and normal maintenance/scheduled turnaround/betterment costs. Similarly, business interruption costs were compiled with reference to market situation and product volumes that were available from inventory.
Business Interruption , Industry Practice/Standard of Care , Operations/Maintenance , Physical Asset Appraisal
Electric Incident Investigation
Conducted a Root Cause Failure Analysis on a power generation facility following the failures of a surge arrester and a backup battery system. Identified required inspection assistance, evaluated failed component inspection results and examined practices and procedures in place at the facility.
Industry Practice/Standard of Care , Operations/Maintenance
Estimate for Fire Rebuild
Developed a cost estimate for replacing and/or purchasing new equipment and materials after damage from plant fire.
Industry Practice/Standard of Care , Operations/Maintenance , Physical Asset Appraisal , Property Damage
Ethylene Plant Construction Litigation
Assisted in a dispute concerning allegations that poor engineering work product contributed to a >$100 million cost overrun.  Assisted with discovery, inspected plant, evaluated construction documents, analyzed the project critical path, and analyzed lost income due to delays in the project schedule.
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Evaluate Biodiesel Production Facility
Provided due diligence review of a biodiesel facility in support of project financing. Reviewed capital costs, operating costs, process technology, and maintenance requirements.
Industry Practice/Standard of Care , Operations/Maintenance , Pricing , Product Quality
Evaluation of Refinery Operating Procedures
Acted as independent advisor in a dispute between a refinery and the Environmental Protection Agency following a period of excess emissions.
Industry Practice/Standard of Care , Operations/Maintenance
Expert Consulting Services
Provided expert consulting services concerning a personal injury incident that involved a weld failure and a release of hydrocarbons.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
FCC NOx Allocation
Prepared a report of FCC regenerator nitrogen oxides (NOx) production that allowed allocation of FCC NOx from a combined refinery stack.  The report was used to negotiate the allowable corporate average NOx limits with the EPA. 
Industry Practice/Standard of Care , Operations/Maintenance
FCCU Construction Litigation
Assisted a major engineering and construction firm in defending allegations that construction errors in the installation of an FCCU catalyst cooler resulted in a significant business interruption claim.  Assisted in discovery, analyzed FCCU operating data, reviewed refinery operating records, evaluated design issues, calculated property damages and business interruption losses, and provided expert testimony.
Business Interruption , EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , Property Damage
Force Majeure Dispute
Provided expert report relating to a claimed force majeure event, due to defects in critical equipment that was required to be installed during a turnaround.  The correction to the defects then resulted in the late delivery of the equipment that extended a petrochemical plant turnaround.   
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Formaldehyde Plant Construction Litigation
Assisted in a dispute concerning allegations that completion delays and poor plant performance at a European formaldehyde plant resulted in a multi-million dollar damage claim.  Assisted with discovery, inspected plant, evaluated plant operating records, reviewed construction contracts, valued the plant, and calculated damages.  Presented and defended conclusions at hearing.
Arbitration , EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Litigation - Fuels Terminal Operations Assessment
Performed expert advice on fuels terminal operations that focused on the practices and procedures with an emphasis on the filling of product tanks.
Industry Practice/Standard of Care , Operations/Maintenance , Property Damage , Safety
Gas Pipeline Rupture Dispute
Performed an independent assessment of the costs incurred, including the lost natural gas inventory, on a ruptured interstate gas transmission line for which the owner requested a multi-million dollar damage reimbursement.  A report was prepared for mediation which resulted in a negotiated settlement.
Industry Practice/Standard of Care , Pipeline , Pricing
Gas Turbine Damage
Assisted in a root-cause analysis and damages dispute concerning a major turbine failure in the start-up of a power plant.  
Industry Practice/Standard of Care , Operations/Maintenance
Gas Well Incident
Prepared expert report on behalf of client versus OSHA.  Matter involved failure of a pipe carrying natural gas that injured one contractor.  OSHA cited client for failure to provided a safe means of pressure relief for vessel (in-line heater) and piping.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Gas Wellhead Equipment Failure
Performed root cause analysis of a gas well casing hanger which led to a well blow out.
Forensic Analysis , Industry Practice/Standard of Care , Operations/Maintenance , Safety
Gasoline Blending Compliance
Provided analysis for a refiner that does not produce finished gasoline on the prospects for producing gasoline that meets all API and ASTM requirements. Analyzed the options available to the refinery for blending reformate fractions and whether aromatics or benzene would likely be the constraining specification as it relates to the "anti-dumping" rule. Evaluated potential early compliance with the EPA's mobile source air toxics (MSAT2) program.
Industry Practice/Standard of Care , Product Quality , Project Feasibility
Gasoline Contamination Dispute
Provided expert report on refinery practices concerning caustic carryover in FCC gasoline mercaptan treaters.  Class action plaintiffs, consisting of retail station owners, alleged underground storage tank damage due to gasoline contamination.  
Industry Practice/Standard of Care , Product Quality
Gasoline Spill Litigation
Assisted in a dispute between a retail marketer and contractor concerning allegations that contractor's work contributed to a gasoline spill from a retail gas station that contaminated the well water of 130 homes.  Assisted in discovery, evaluated the mechanical integrity of equipment, examined unique theories of causation, inspected site, and attended destructive testing procedures.
Industry Practice/Standard of Care , Operations/Maintenance
Heliport Pipeline Leak
Prepared expert rejoinder report on leakage from fuel storage, pipeline, and loading system located at a heliport and marine dock.
Industry Practice/Standard of Care , OSHA-related
HF Alkylation Incident
Investigated facts related to pump casing rupture where hydrofluoric acid was released. Reviewed refinery operations, training, and safety practices. Advised attorneys on generally accepted industry engineering practices and standards regarding design, operation, and maintenance of hydrofluoric acid alkylation unit.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Historical Refinery Waste Generation
Provided expert report on the probable types and amounts of wastes produced by a refinery during its 50-plus year operating life. Study was part of litigation involving assignment of responsibility for an EPA superfund site.
Environmental , Industry Practice/Standard of Care , Operations/Maintenance
Hurricane Rita Claim
A petrochemicals facility experienced a loss of steam supply from an outside steam supplier and a subsequent unscheduled shutdown which, in turn, resulted in production losses and major damage to the facility.  The steam supplier attributed the steam outage to boiler damage caused by a hurricane, which had made landfall several months earlier.  Assisted by investigating the link between the hurricane and the steam supplier boiler outages.  
Industry Practice/Standard of Care , Operations/Maintenance
Incident Analysis - Petrochemicals
Performed an investigation analysis following fire and explosion incidents at a major Gulf Coast manufacturing facility.  The engagement entailed development of the sequence of events, root cause analysis, assessment of the decision to rebuild, and reconstruction monitoring.  An independent project schedule and cost estimate for the plant reconstruction was developed.
Business Interruption , EPC-related , Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Property Damage , Safety
Independent Engineer
Retained as the Independent Engineer for the "grassroots" Tangguh LNG Liquefaction Project in Indonesia.  Prepared the technical due diligence for the US$3 billion facility on behalf of a financial consortium.
Industry Practice/Standard of Care , LNG , Pricing , Project Feasibility
Industrial Incident
Investigated cause of dust cloud deflagration at a Vitamin E production facility. Assessed that bulk solids handling procedures were modified without considering the original safety design basis for the equipment. Developed expert opinions on causation.
Industry Practice/Standard of Care , Operations/Maintenance , Safety
Insurance Arbitration
Investigated the circumstances surrounding an oil spill at a Gulf Coast refinery following a hurricane.  Work focused on whether the refiner acted as a "prudent operator" before and after the hurricane and whether the owner was entitled to a claim for damages based on an insurance policy's pollution exclusion clause.  Prepared a written report for submission into evidence in an international arbitration.
Arbitration , Industry Practice/Standard of Care , Operations/Maintenance
Insurance Litigation of Refinery Environmental Contamination
Provided expert witness testimony and analysis in the litigation of insurance coverage for previous environmental contamination of petroleum refineries located on the East Coast, West Coast, and Midwest.  Evaluated both liability and damage claims based on the multiple insurance contracts for each site.  
Industry Practice/Standard of Care , Operations/Maintenance
Interstate Pipeline Inspection Practices
Provided expert testimony on inspection and maintenance practices for interstate petroleum products pipelines. Issues included reasonable depth of additional overfill and width of maintenance right-of-way.
EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , Pipeline
Investigate Refinery Heater Explosion
Performed root cause analysis of an explosion at a refinery heater and identified contributing factors. Performed a review of safe operating procedures, including shutdown and start-up of heaters. Provided expert testimony.
Expert Witness/Testimony , Forensic Analysis , Industry Practice/Standard of Care , Operations/Maintenance , Property Damage , Safety
Jet Fuel Contamination Dispute
Following product quality issues in major interstate product pipeline movements, reviewed product injection practices and analyses at pipeline injection point. Evaluated analyses at various points along the pipeline to assess possibility of quality degradation.
Industry Practice/Standard of Care , Operations/Maintenance , Pipeline , Product Quality
Lender's Independent Engineer
Served as independent engineer for a "grassroots" olefins project.  Prepared the technical due diligence for a US$4 billion facility on behalf of international export credit agencies and onshore and offshore lenders.
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Litigation - Wastewater Treating
Provided expert consulting support for a refinery wastewater treating environmental criminal matter. The work required previous experience with and a solid understanding of the plant processes and equipment which are used in treating industrial wastewater.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
LPG Pipeline Contamination
Evaluated pipeline contamination and potential sources of contaminants from various sources.
Industry Practice/Standard of Care , Operations/Maintenance , Pipeline , Product Quality
M&A Dispute
Evaluated the foreseeability of project cost overruns that negatively impacted the economics of the acquisition of an EPC Firm.
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Manufactured Gas Plant
Provided technical assistance and review of historical documents in support of litigation regarding the environmental cleanup of a manufactured gas plant site.  The site, which had various gasification units in operation between approximately 1870 to 1950, had been used for a number of other purposes.  Analysis investigated the contamination present at the site to all previous and current gas plant operations.
Environmental , Industry Practice/Standard of Care , Operations/Maintenance
Marine Terminal Development
Reviewed design requirements and monitored construction, start-up, and operation of a project to develop a bulk liquids terminal.  Work included review of dredging requirement, schedule, and interfaces between this project and a project to export ammonia from the terminal.
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance , Waterborne/Marine
Midstream Acquisition Due Diligence
Assisted energy distribution company with due diligence for potential transaction involving gas gathering and processing assets located in the Permian Basin.  Assets evaluated included over 4,000 miles of gas and liquid pipelines, four gas processing plants, and multiple gas treating plants.  Participated in data room reviews and management presentations with a focus on commercial, operational, and technical evaluations of midstream systems.  Developed comprehensive economic model of the integrated gathering and processing assets that was used to determine valuations and evaluate key sensitivities.
Industry Practice/Standard of Care , Operations/Maintenance , Physical Asset Appraisal , Pipeline , Pricing
Natural Gas Production Facilities
Served as one of two project managers responsible for the engineering, procurement, and construction of a 200 million cubic feet per day natural gas recovery facility in central Algeria to provide the feedstock for a new liquefied natural gas (LNG) plant on the Algerian coast. At the time of installation, the $250-million project was the largest of its kind in the world. Conducted negotiations with local labor, equipment, and utility suppliers. Arranged meetings with local environmental agencies to ensure compliance with all national environmental rules and regulations.
EPC-related , Industry Practice/Standard of Care , LNG , Operations/Maintenance
Natural Gas Royalty Litigation
Evaluated the design and historical capital costs of a natural gas pipeline system in western Oklahoma. Reviewed system material balances and operator's natural gas measurement practices.
Industry Practice/Standard of Care , Operations/Maintenance , Pipeline , Pricing
New Petroleum Products Terminal
On behalf of a major international construction company, prepared a preliminary feasibility study on a new petroleum products import terminal to serve the local market .  Study included facility layout and size estimates for docks and storage tanks.
Industry Practice/Standard of Care , Pipeline , Project Feasibility , Waterborne/Marine
Nitroparaffins Litigation
Assisted in a dispute between an operator and and EPC firm concerning allegations that the process design contributed to an explosion at a nitroparaffins manufacturing plant.  Assisted in discovery, evaluated design issues, and provided expert testimony.
EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Offshore Pipeline Failure
Following a business interruption claim concerning number of failures on a large subsea crude oil pipeline, examined original construction specifications, maintenance, inspection, and operation records of the pipeline.  Also reviewed the repair plans and repair execution of the failed components and made recommendations to include:  a) comprehensive metallurgical analyses; b) preparation of an efficient repair and execution schedule; and c) complete subsea modeling of the pipeline for the purpose of failure mode and time to failure predictions.    
EPC-related , Industry Practice/Standard of Care , Offshore , Operations/Maintenance , Pipeline
Offshore Pipeline Project
Served as Independent Engineer on behalf of a major financial institution for a $200 million project to build a deepwater gas and oil-gathering system. Prepared a valuation of offshore pipelines and an onshore gas processing plant for gathering and processing of deepwater Gulf of Mexico oil and gas production in support of structured finance. Certified completion of the project for financial purposes.
EPC-related , Industry Practice/Standard of Care , Offshore , Operations/Maintenance , Pipeline
Offshore Platform Design
Assessed design of elevated platform and ladders on a jack-up oil derrick which was under construction.  Compared design to industry standards.
EPC-related , Industry Practice/Standard of Care , Offshore
Paraxylene (PX) Contract Dispute
On behalf of a major international buyer of paraxylene, prepared an expert analysis concerning damages claimed by a large US based supplier.  Analysis included a detailed evaluation of supplier's paraxylene manufacturing economics.
Business Interruption , Industry Practice/Standard of Care , Operations/Maintenance , Pricing
PVC Plant Litigation
Assisted in a dispute concerning allegations that an explosion at a major manufacturer of PVC resins was due to a poor process design that failed to meet government regulations and engineering standards.  Assisted in discovery, inspected the plant, evaluated procedures and work methods, reviewed applicable standards, and reviewed operating records.  
Forensic Analysis , Industry Practice/Standard of Care , Operations/Maintenance
Propane Product Quality Dispute
Investigated the design and operation of a natural gas liquid fractionation, storage, and loading facility located on the Red Sea to determine potential causes of alleged hydrogen sulfide contamination of propane cargoes.
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance , Product Quality
Polyurethane Foam Litigation
Assisted in claims concerning polyurethane foam system products that were alleged to be defective or unfit for their intended use.  Assisted in discovery, observed and reviewed work environment and work methods, evaluated manufacturing records, reviewed warranty claims, and prepared trial exhibits.
Industry Practice/Standard of Care
Pulp and Paper Mill Incident
Analyzed processing operations and engineering design in a pulp and paper mill to determine sequence of events and possible causes of incident.
Industry Practice/Standard of Care , Operations/Maintenance , Safety
Sulfuric Acid Storage Incident
Retained to assist in the investigation of a fatality incident at a sulfuric acid processing and storage facility.  Reviewed equipment design, inspection and repair history, operating procedures, training of personnel, and industry practices.  Assisted legal team with on-site investigation and interaction with local, state, and federal agencies.  Reviewed conclusions by root cause analysis for consistency and factual support.
Forensic Analysis , Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Thermal Radiation Exposure
Investigated an incident involving a claim of thermal radiation exposure during a refining unit fire.  Engineering reports, videos, weather conditions, unit design drawings, and published literature on levels of heat exposure from large hydrocarbon fires were evaluated.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Salt Water Disposal Tank Explosion
Investigated the cause and origin of a storage tank explosion at an oil and gas salt water disposal facility in Colorado. Conducted site investigation and facility/equipment inspections, evaluated system design and operation, and conducted witness interviews. Determined cause of explosion and worked with company management to evaluate existing policies and procedures for potential areas of improvement.
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Physical Asset Appraisal , Safety
Underground Storage Tanks Claim
Assisted in a dispute concerning an allegation that Underground Storage Tanks (USTs) at a retail outlet had released gasoline vapors, resulting in contamination of groundwater with MTBE. Assignment included review of procedures for delivery of gasoline from tankers to UST, review of equipment and fittings used in UST, review of hydrogeological data regarding groundwater and contamination plumes, review of the design of vapor recovery systems, and calculations of vapor composition and amounts released. Prepared report to document findings and testified in deposition.
Environmental , Expert Witness/Testimony , Industry Practice/Standard of Care , OSHA-related , Toxic Tort
Review of Facilities Safety Issues
Assisted in technical review of safety related issues at crude oil production and gathering facilities.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Pipeline , Safety
Root Cause Analysis
Conducted a Root Cause Failure Analysis on a high pressure steam turbine that failed following a planned outage at a cogeneration power plant. Evaluated outage work procedures, actual outage work undertaken, start-up monitoring results, and post-failure turbine inspection results on turbine disassembly.
Forensic Analysis , Industry Practice/Standard of Care , Operations/Maintenance
Refinery Restart Due Diligence
Performed a site inspection and advised potential investor regarding the technical and commercial viability of restarting a refinery that had been shut down for several years.
Industry Practice/Standard of Care , Operations/Maintenance , Project Feasibility
Reciprocating Compressor Accident
Reviewed details of non-fatal accident involving a restart of skid-mounted gas compression machinery at a producing well. Upon investigation of the facts, prepared report detailing the proximate cause of the incident.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Pipeline Contamination Dispute
Assisted in a claim involving an alleged y-grade/NGL pipeline contamination from a gas processing facility.  Examined the following key areas to evaluate the claim: pipeline hydraulics, laboratory records, chronology of pipeline sample data, reasonableness of claimed expenses, gas processing facility operation, and records.   
Business Interruption , Industry Practice/Standard of Care , Operations/Maintenance , Pipeline
Tank Truck Explosion Investigation
Investigated the potential causes and sources of ignition for an explosion that destroyed a road tanker, used to haul raw natural gas liquids from a gas treating plant, that was in a repair shop for the replacement of a pressure relief valve. 
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Petroleum Refinery Dispute
Provided overview of turnaround practices and industry standards utilized in the United States and Europe.  Evaluated decisions and practices utilized at the subject refinery to determine if those decisions were in compliance with standard practices and whether a decision to optimize the turnaround execution date was a factor in a plant incident.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Pressure Vessel Failure
Investigated the cause of a hydrocarbon release resulting from the brittle fracture of a pressure vessel during start-up at a petrochemical plant. Incident involved multiple injuries and deaths and extensive property damage. Issues studied include ethylene plant design, operating practices and procedures, start-up operations, instrumentation, and safety training.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Polyolefins Plant Explosion
Assisted attorneys and company in preparation for litigation and negotiation with government agencies while investigating the cause of an explosion which caused the death of over 20 people. Assisted risk management in preparing and negotiating property damage and business interruption claims in excess of $1.3 billion.
Business Interruption , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Property Damage , Safety
Polybutylene Pipe Litigation
Assisted municipal water districts in asserting claims for tens of millions of dollars in damages resulting from defective polybutylene pipe.  Assisted in discovery, evaluated research and development records, reviewed state-of-the-art issues, and provided expert testimony.
Expert Witness/Testimony , Industry Practice/Standard of Care , Pipeline , Product Quality
Polypropylene Manufacturing
Assisted in a dispute concerning insurance claims for property damage and business interruption in connection with a reactor incident during construction of a production facility.  
Business Interruption , EPC-related , Industry Practice/Standard of Care , Property Damage
MTBE Litigation
Prepared declaration of gasoline distribution issues in northern California, including rebuttal of other experts' analyses of gasoline distribution.
Industry Practice/Standard of Care
Coal Gasification Plant Accident
Provided assistance to a mechanical contractor for a root-cause investigation of a fatal accident at a coal gasification plant.
Gasification , Industry Practice/Standard of Care , Operations/Maintenance , Safety
Refinery Force Majeure Claims
Prepared expert reports and testified in an international arbitration involving multiple product supply disputes between a refinery and an adjacent chemical plant. Reviewed force majeure claims related to catalytic cracking technology, product supply contracts, and utility supply interruptions.
Arbitration , EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Petrochemical Terminal Fire
Reviewed testimony, expert reports, and forensic evidence and attended depositions to determine cause and origin of terminal fire.  Prepared report addressing electrostatic discharge theory, petrochemical handling procedures, employee training, and management issues. 
Forensic Analysis , Industry Practice/Standard of Care , Safety
Gas Processing Metallurgy Replacement
Evaluated the reasonableness of a large project’s cost to replace the piping with a different metallurgy for a high-pressure, high-temperature sour gas reinjection facility in Central Asia.  Also opined on the industry knowledge of the proper metallurgy at the time of construction of the original facility.
EPC-related , Industry Practice/Standard of Care
Fall Protection Evaluation
Investigated circumstances concerning the injury to a person who fell from a loading dock.  Provided opinions regarding general safety requirements, industry practices, and fall protection requirements for this type of activity.
Industry Practice/Standard of Care , OSHA-related
MTBE Litigation
Supported joint defendants in litigation involving alleged MTBE contamination in groundwater. Analyzed gasoline supply issues to central Illinois over the period 1980 to 2006. 
Industry Practice/Standard of Care
Natural Gas Gathering Disputes
Provided expert report regarding claims involving natural gas measurement, prudent operations, natural gas pricing, surface estate issues, reasonable accommodations, and environmental considerations.
Industry Practice/Standard of Care
Oil Field Pipe Dispute-Insurance Claim
Reviewed a claim involving an insurance dispute relating to proper preservation of drilling pipe in a storage yard following a hurricane.
EPC-related , Industry Practice/Standard of Care
Pipeline Pigging Accident
Reviewed injury accident that occurred while pigging a gathering pipeline to remove formation water produced with natural gas. Provided an expert report regarding applicable industry standards regarding operation of vacuum truck for disposal of formation, as well as observations regarding the contractual responsibilities of the tank truck operator and the production operator.
Industry Practice/Standard of Care , Pipeline , Safety
Refinery Contractor Indemnification Dispute
Provided expert opinion concerning an indemnification dispute between a refiner and contractor, as well as the standard of care and practice in the industry concerning the design and construction of a piping relief system.  Also opined on the refinery owner’s responsibilities concerning the acceptance and maintenance of completed piping systems.
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Gas Producer Contractual Dispute
Provided expert report and testified in federal bankruptcy court concerning disposal costs of produced salt water, reasonableness of a farm-out joint venture agreement, costs of capital, and salvage value of production equipment.
Industry Practice/Standard of Care
MTBE Litigation
Provided expert report that evaluated and discussed the issues concerning why MTBE was chosen over ethanol to the federal oxygenate requirements in the early 1990s.  Also included was a discussion of how gasoline was supplied to the local region in California over the 1990s and early 2000s. 
Industry Practice/Standard of Care
Wellhead Value - Natural Gas
Provided opinion with respect to effect of capital recovery of production facility costs on wellhead value of natural gas.
Industry Practice/Standard of Care , Pricing
Project Development Dispute
Prepared an expert report and delivered a deposition and testimony at jury trial in a dispute involving a project development claim. The dispute focused on the value and likelihood of successful completion for two projects in the early stages of development: a natural gas salt dome storage facility and a petroleum products terminal.
Expert Witness/Testimony , Industry Practice/Standard of Care
Dispute Support - Groundwater Contamination
Provided expert witness support regarding a groundwater contamination claim at a closed refinery. Provided opinions regarding the standards of care and operation of the former refinery. Prepared a written expert report.
Environmental , Industry Practice/Standard of Care , Operations/Maintenance
Tube Sheet, Flare Tip Matter
Investigated the cause of tubesheet and flare tip damage related to an unplanned sudden shutdown of the facility.  Evaluated whether damage was caused by the shutdown, long-term wear, or contractor error during installation.  Provided expert support through mediation and settlement efforts.  
EPC-related , Industry Practice/Standard of Care , Operations/Maintenance
Biodiesel Plant Construction Dispute
Evaluated engineering and construction practices in a dispute between an owner and EPC contractor due to cost overruns.  Issues included engineering and project management practices which required rework, and construction practices which created safety and operability issues.  Cost estimates were prepared for correcting the deficiencies.
EPC-related , Industry Practice/Standard of Care
Gas Compressor Incident Dispute
Provided expert opinions concerning a gas compressor failure insurance claim related to:  (1) evaluating the gas processing facilities' maintenance and standard of care practices compared to industry standards; and (2) reviewing the operating practices and programs utilized at the facility to determine if these practices caused or contributed to the incident and subsequent damage.
Industry Practice/Standard of Care , Operations/Maintenance
Gas Treating Facility Explosion Investigation
Investigated cause of system overpressure and shutdown of downstream pipelines which led to flange gasket failure and fire.  Reviewed system design, construction, and overpressure protection at wellheads located upstream to determine cause of failure.   
EPC-related , Industry Practice/Standard of Care , Pipeline , Safety
Review Infrastructure Assets
Assisted client in evaluating infrastructure spending to support ongoing operations and maintenance activities.  Our review evaluated whether  the infrastructure assets were integral to the overall technological complex.
EPC-related , Industry Practice/Standard of Care
Condensate Gathering System Due Diligence
Assisted client with engineering due diligence on a Texas condensate gathering system focusing on pipeline mechanical integrity issues.
Industry Practice/Standard of Care , Physical Asset Appraisal , Pipeline
Supply Contract Dispute
Assisted in breach of contract claims regarding a helium supply agreement from a large natural gas processing/treating complex.  Analyzed historical operation and performance of processing and extraction facilities, including sources and composition of gas supplies, plant shutdowns, and plant turndown capabilities.  Reviewed plant performance, including operating costs, efficiencies, and operating modes to support defendant's plant operations.
Industry Practice/Standard of Care , Operations/Maintenance , Product Quality
Terminal Operations
Provided litigation support assistance and expert opinion for case involving historic Standard of Care issues with petroleum product terminals.
Environmental , Industry Practice/Standard of Care , Operations/Maintenance , Toxic Tort
Performance Improvement Initiatives in Worldwide Refineries
Helped design and direct a consulting project to identify the most successful profit improvement initiatives at top performing worldwide refineries. Audited and examined company culture, energy usage, refinery losses, personnel training, safety practices, environmental controls, process operations, technical services, administration, planning and economics, capital investments, maintenance, and reliability factors. Identified and documented those initiatives, which proved most successful, including their duration, need, and value added. Assignments were in the U.S., U.K., Romania, Korea, and West Africa.
Industry Practice/Standard of Care , LP/Planning Practice , Operations/Maintenance , Pipeline , Pricing
Maintenance and Reliability Improvement Program
Managed the development of a client’s routine maintenance and reliability improvement program that identified areas of concern and implemented new work practices aimed at improving competitiveness. Efforts reduced maintenance costs and improved operating performance.
Industry Practice/Standard of Care , Operations/Maintenance , Pipeline
Turnaround Optimization Studies
Performed numerous turnaround optimization studies and execution reviews for refineries and petrochemical companies worldwide. Areas of focus included analyzing the work selection process, reviewing work execution schedules, evaluating the facilities preparedness to perform the turnaround, and optimizing turnaround cycles or start dates.
Industry Practice/Standard of Care , Operations/Maintenance , Pipeline
Maintenance Contracting Strategies
Worked with international clients to analyze existing maintenance and turnaround contracting strategies, contractor availability, and local cultures to identify areas of concern and develop strategies for improvement.
Industry Practice/Standard of Care , Operations/Maintenance , Pipeline
Reliability and Maintenance Continuous Improvement Initiatives
Improved efforts to eliminate equipment defects and unscheduled outages by developing and incorporating the use of reliability indices to identify problem equipment. Reliability teams were then able to prioritize concerns to focus reliability improvement initiatives in areas of highest risk to safety, operational performance, and profits. This defect elimination program was utilized as the cornerstone for the plant’s continuous improvement initiatives.
Industry Practice/Standard of Care , Operations/Maintenance , Pipeline
Pipeline Operating Dispute
Assisted in a dispute between an owner and an operator of a recently-constructed crude oil pipeline.  Prepared an expert report concerning:  (1) the facilities that should have been provided as part of the capital project to construct the pipeline; (2) the equipment necessary to operate and maintain the pipeline; and (3) whether defects found during the early operating period were the result of improper equipment design specifications and construction, or improper operation and maintenance.  Testified at arbitration in London.
Arbitration , Commercial Terms Review , Environmental , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , Pipeline
Marine Accident Investigation
Investigated causes for contamination of a cargo of residual fuel aboard a barge that exploded and sank.
Industry Practice/Standard of Care , Operations/Maintenance , Product Quality , Property Damage , Safety , Waterborne/Marine
Performance Improvement - Petrochemicals
Assisted in a global study focused on analyzing the operating performance of steam crackers.  Participated as a member of a multi-disciplined team responsible for: reliability and operations data gathering, analysis, plant personnel interviews, and industry benchmarking of performance.  The study concluded with numerous recommendations to company senior management aimed at improving worldwide plant operational availability.
Industry Practice/Standard of Care , Operations/Maintenance
Heat Exchanger Failure Investigation
Investigated cause and events surrounding the rupture of process precooler involving one fatality. Assisted outside counsel by evaluating plant maintenance, safety and operator training procedures compared to industry accepted practices, as well as developing an understanding of probable circumstances that led to the event.
Industry Practice/Standard of Care , Operations/Maintenance , Safety
Pump Failure Investigation: Maintenance Shop
Reviewed rotating equipment maintenance shop's pump maintenance and rebuild procedures. Provided written report describing potential causation of power plant rotating equipment failures and recommendations to improve maintenance shop quality control.
Industry Practice/Standard of Care , Operations/Maintenance
Air Compressor Incident Investigation
Provided independent assessment of an accident that occurred at a container manufacturing facility involving an air compressor and high pressure piping. Efforts included reviewing the compressor operators' work practices and potential causes of the incident.
Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Heat Exchanger Failure Investigation
Investigated circumstances concerning a heat exchanger failure that resulted in a fire and explosion, fatally injuring several employees. Investigation included evaluating relevant operating records and comparing these with design specifications to evaluate whether exchanger was operated, inspected and maintained in accordance within design parameters and industry practices. Prepared expert report.
Industry Practice/Standard of Care , Operations/Maintenance , Safety
Hydrogen Sulfide Incident Investigation
Following a fatality caused by exposure to hydrogen sulfide at a crude oil storage tank with a known sour gas atmosphere, investigated the causes for the incident and the operating and maintenance practices (standard of care) with respect to: supervision, training, and use of personal protective equipment.
Industry Practice/Standard of Care , OSHA-related , Safety
Equipment Demolition / Fire Investigation
Investigated circumstances of a large refinery fire related to a hydrocarbon release from a partially demolitioned open-ended pipe. Developed expert report of findings and provided opinions concerning industry practices and standards of care for the demolition of decommissioned facilities. Provided deposition and arbitration testimony.
Arbitration , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , Safety
Fall-Related Injury Investigation
Investigated circumstances concerning the personal injury of a contract employee who fell inside a flue gas system during a refinery turnaround.  The investigation included evaluation of:  (1) refinery safe work practices compared to industry standards; (2) utilization of fall arrest systems to mitigate the presence of fall hazards; (3) the responsibilities of both operating companies and contractors to recognize and develop plans to mitigate fall hazards; and (4) responsibilities of both parties to execute and communicate turnaround work plans.
Industry Practice/Standard of Care , OSHA-related , Safety
Flare Tower Design Review
Independently reviewed the design of two flare towers for an LNG onshore facility. Commented on the EPCM contractor's responsibilities to review the work product of subcontractors and vendors.
EPC-related , Industry Practice/Standard of Care , LNG
Hot Tap Incident
Evaluated and incident involving a "hot tap" on processing pipeline and resultant leak. Assisted refinery owner and outside counsel in action brought against maintenance contractor.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Port of Houston Power Disruption
Reviewed the power outage caused by a contractor at a Port of Houston container facility, to assess the Contractor's potential exposure to claims from the Port Authority.
Business Interruption , Industry Practice/Standard of Care , Property Damage
Drilling Incident Investigation
Following an incident on an oil drilling platform, assisted with the investigation to discern whether relevant practices, e.g., API and others, were followed.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Water Treatment/Injection Contract Dispute
Engaged to provide expert witness assistance with technical issues regarding water treatment facilities.  Reviewed project, maintenance and operational costs and schedules, in addition to the performance of the facilities.  Testified in an ICC arbitration hearing in New York conducted in Spanish/English.
Arbitration , EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Tank Collapse Assessment
Assessed contractor work practices associated with the collapse of  a storage tank that occurred during cleaning operations.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , Property Damage , Safety
Gas Plant Due Diligence
On behalf of a developer's due diligence process, provided an independent review of a gas plant project in the U.S.  Reviewed documents and consulted with the developer regarding the process design, engineering, major systems and equipment, procurement, construction, schedule and CAPEX. 
EPC-related , Industry Practice/Standard of Care
Ethanol Plant Freeze Claim
Reviewed an insurance claim associated with an idled ethanol manufacturing facility being re-started.  Purpose was to assess items listed in the claim to determine if damages were caused directly by a winter freeze or due to some other failure mechanism such as improper mothballing techniques or normal degradation of a once-operating facility.
Business Interruption , Industry Practice/Standard of Care , Operations/Maintenance , Property Damage
Faulty Equipment Claim
Assisted refinery operator with an insurance claim concerning the delivery and operations of a faulty air cooler.  Reviewed documentation and supported client to determine roles and responsibilities of the equipment supplier to design, fabricate and deliver equipment free from manufacturing defects.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , Property Damage
Refinery Turnaround Dispute Arbitration
Investigated the cause/origin of a leak that developed on a process unit after a turnaround, leading to an extended shutdown.  Evaluated various damage models used to estimate the value of loss of use of the process unit and the reduced operation of the refinery.  Submitted an expert report on the leak liability issues and the estimated value of loss of use of the process unit and its effects on refinery operations.  
Arbitration , Business Interruption , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Gas Plant Construction Dispute
Prepared expert report and testified regarding alleged performance deficiencies of a general mechanical contractor performing a reimbursable construction project.  The project allegedly experienced poor productivity, resulting in cost overruns and schedule delays.  Assessed the different potential causes of alleged poor productivity, including project management, scope changes and weather impacts.
Arbitration , EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care
EPC Construction Dispute
Provided expert support in a construction dispute relating to a natural gas processing plant in North America.  The dispute primarily concerned engineering design issues and whether the installed facilities met contract, specification, and industrial standard requirements.
EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Fracking Equipment Fire
Assisted with the Cause and Origin investigation of a fire on a blender used in a fracking operation.   
Expert Witness/Testimony , Forensic Analysis , Industry Practice/Standard of Care
Standard of Care During Ethylene Plant Outage
Reviewed the shutdown and subsequent start-up of an ethylene plant following a utility outage.  Reviewed liquidated damage calculations.
Industry Practice/Standard of Care , Operations/Maintenance
Electrical Supply Disruption
Following the sudden loss of electrical supply to a chemical plant, which resulted in equipment damage, the chemical plant owner claimed that the electricity supplier was negligent.  In addressing the root cause of the equipment damage, our work assessed the following parameters: (1) the nature of the supply contract; (2) the nature of the outage - whether intentional or inadvertent; (3) the chronology of events following the outage; (4) the designs of the electrical systems in question; and (5) the operational procedures in the event of a power outage and whether they were followed.
Business Interruption , Industry Practice/Standard of Care , Operations/Maintenance , Property Damage
IPP/Refinery Power Generation Outage Dispute
Assessed the cause(s) of supplier's steam and electricity generation failure and mitigating actions by the refinery/petrochemical customer. Preliminary findings and a document request were provided to the client.
Arbitration , Business Interruption , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , Property Damage
Insulation Works Dispute
Provided expert witness assistance with technical issues regarding the installation of insulation on an LNG facility.  Baker & O'Brien reviewed the technical issues, prepared an expert report, and testified regarding our opinions in an ICC Arbitration hearing.
Arbitration , EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care , LNG
Pulp and Paper Mill Construction Dispute
Opined on engineering standard of care issues and issued an expert report for use in a dispute between the owner of a pulp and paper mill and an engineering firm as it related to a major turnaround project.
EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care
Floating Production Platform Dispute
Reviewed, opined, and prepared expert report regarding the project cost differences experienced during construction of the hull and integration of topsides for a semi-submersible platform, which was placed into service offshore of Brazil.  Our review included a change in the construction site, changes in construction strategy, and changes in the sequence of construction. 
Arbitration , EPC-related , Expert Witness/Testimony , Industry Practice/Standard of Care , Offshore
Pipeline Operating Practices
A lawsuit was filed against a major U.S. pipeline company stating that its operating practices during maintenance at a gas gathering line resulted in a fire and the injury of two contract workers who were the plaintiffs. We were asked to opine on the cause of the fire. The matter was settled out of court prior to reports being issued or testimony being presented.          
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , Pipeline
Refinery Construction Dispute
Assist client and provide expert consulting support assessing responsibilities of an EPC contractor, as well as project execution and start-up issues associated with the construction and start-up of a grassroots refinery. 
Arbitration , Business Interruption , EPC-related , Industry Practice/Standard of Care , Operations/Maintenance , Property Damage
Natural Gas Measurement Dispute
Assisted client with a "Discovery Request" regarding measurement of shale-play natural gas from a field meter.   Reviewed accounting records, photos, and meter specifications to determine if consistent with industry standards for measuring natural gas.  
Commercial Terms Review , Industry Practice/Standard of Care , Operations/Maintenance
Retail Marketing Contamination Dispute
A gasoline marketer that had withdrawn from a particular region was being sued for alleged contamination from leaking underground storage tanks at retail marketing locations in that region. We were retained to provide an overview of the gasoline supply chain with an emphasis on the various types of retail operations and to review the plaintiffs’ claims regarding the number of retail outlets that were owned and controlled by that company in the relevant time period.
Environmental , Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance
Oil Company Due Diligence
Retained to visit data room and prepare due diligence report summarizing facilities and environmental information for multiple oil fields and an oil processing and export terminal. 
Industry Practice/Standard of Care , Physical Asset Appraisal
Propane Quality Review
Reviewed claims regarding a propane quality dispute between a supplier at a new terminal and a retail distributor.  Reviewed propane quality test results and bills of lading to compare actual versus reported quality.  We provided technical findings to client and assisted in getting the matter settled.
Industry Practice/Standard of Care , Operations/Maintenance , Product Quality
Refinery Flare Incident
Following a fire during a scheduled flare system maintenance turnaround, retained to assess the feasibility of safely hot tapping the flare header to install a stopple and allow removal of a large gate valve upstream of a flare knock-out drum.  In consultation with other parties, assessed: (1) the flare system equipment, (2) the refinery hot tap procedures, and (3) evaluated if the activities could be performed safely.
Expert Witness/Testimony , Industry Practice/Standard of Care , Operations/Maintenance , OSHA-related , Safety
Accident Liability
Assisted in a personal injury claim following an incident in a petroleum refinery process unit.  Examined refinery conformity with the latest available industry technology, regulations, standards, and practices.  
Industry Practice/Standard of Care , OSHA-related , Safety